The following projects are currently advertised for bids. Interested bidders may find general information about each project, as well as printable actual Contract Documents in PDF format. The general information is the same project description provided to Newspapers and by direct mail solicitations. The Contract Documents include the Drawings and the entire Project Manual. Drawings can be printed on any regular or large format printers. The Project Manual includes Proposal Forms, Front End Documents, General and Supplementary Covenants, and Technical specifications. All these are also completely printable.
Effective October 2009, the Department will no longer be responsible for providing hard copy notice to bidders or addenda to either contractors or plan rooms. An email listserv has been created to communicate electronically with vendors currently on file with the DNR. As a member of this listserv, you will receive electronic notice to bidder information on a regular basis.
To subscribe to this list, click here.
The Department will be utilizing the vendor Beeline and Blue to provide printed copies of Plans and Specifications and Addenda upon request. The department will no longer provide complimentary copies of Plans and Specifications to contractors or sub-contractors after award of the contract. Please visit dfs.beelineandblue.com/iowa or contact (515) 244-1611 for more information.
To access any of these, unless you have already done so, you will need to download and install Acrobat Reader from the Adobe Website.
You may obtain a free download from
Click on the project names below to view the one(s) which interest you.
This project consists of installing a portland cement concrete access road which will be connecting to an existing road creating a one-way loop road with parking along the right side of the loop road located at Ledges State Park in Boone County, Iowa and includes grading, installation of concrete road with parking along with pavement striping for the parking spaces and one-way street signage.
This project consists of cleaning existing culverts, reshaping ditches, placing rock on shoulders and rock roads, placing revetment and erosion stone, rock check dams, patching, cleaning and filling cracks and fog sealing approximately 1.64 miles of HMA pavement of varying widths.
ESTIMATED QUANTITIES:
Clearing and Grubbing
1 L.S.
Removal of Pavement
6.7 S.Y.
Asphalt Emulsion-Fog Seal (Pavement)
982 GAL.
Patches, Full-Depth Finish, 6-inch, By Area, HMA
68.1 S.Y.
Patches, Full-Depth Finish, 6-inch, By Count, HMA
5 Each
Subbase (Patches)
14.5 C.Y.
Transverse Joint Repair
44 Tons
Crack and Joint Cleaning and Sealing (HMA Surfaces)
1.64 MI.
Sealer Material (HMA Surfaces)
820 LB.
Longitudinal Joint Repair (HMA)
3,332 L.F.
Paved Shoulder, HMA, 6"
6.7 S.Y.
Granular Surface On Road, 1"
418 Tons
Granular Shoulder, 1 1/2" Minus
5 Tons
Revetment, Class E
38 Tons
Erosion Stone
13 Tons
Reshaping Ditch
0.92 STA.
Clean-Out Pipe Culvert
50 L.F.
Clean-Out Intake
1 Each
Rock Check Dam
18 L.F.
Painted Pavement Marking, High-Build Waterborne, 6" Crosswalk Line, White
ARCHERY BUILDING AND COURTYARD IMPROVEMENTS (CONTRACT)
Proposal Guarantee: $37,500
Completion Date: 7/15/2024
Current operations at the Fair have temporary facilities for the air rifle and archery demonstrations. This project will provide a permanent solution for this activity, making it safer, easier to access, and more enjoyable for everyone. While relocating this portion to the north side of the courtyard, the stage where presentations are delivered will have to be moved to the south-west corner of the courtyard. This move will provide accessibility to all and will also reduce noise from adjacent activities at the fair. The North end of the courtyard will also be renovated for better circulation, permeable pavers, and native plantings will be installed.
ESTIMATED QUANTITIES:
Mobilization
1 L.S.
Demolition
1 L.S.
Construction Staking
1 L.S.
Class 10 Excavation, Common Excavation
150 C.Y.
Class 10 Excavation, Waste
50 C.Y.
Subgrade Preparation
328 S.Y.
Bioretention Cell Soil Media, 18" Layer
25 C.Y.
Choker Aggregate, 3" Layer
8 Tons
Aggregate Subbase, 12" Layer
29 Tons
6" Subdrain
261 L.F.
8" Subdrain
34 L.F.
Storm Sewer, Trenched 8" HDPE
22 L.F.
Subdrain Cleanout, Type A-1, 6"
4 Each
Subdrain Cleanout, Type A-2, 8"
1 Each
SW-512 Circular Area Intake, 18" W/ SW-604 Type 3A Casting
1 Each
SW-512 Circular Area Intake, 24" With Solid Casting
1 Each
8" Trench Drain
17 L.F.
Trench Drain PCC Channel
3 C.Y.
Corten Steel Channel. 12"
1 L.S.
6" PCC With Decorative Finishes, 6" Thickness
3 S.Y.
Permeable Pavers
280 S.Y.
Bedding/Joint Filler Aggregate, 2" Layer
29 Tons
Filter Aggregate Subbase, 4" Layer
59 Tons
Storage Aggregate Subbase, 8" Layer
109 Tons
PCC Edge, Permeable Paver Edge Restraint
504 L.F.
Soil Separation Fabric
315 S.Y.
Metal Landscape Edging
101 L.F.
Permanent Seeding, Fertilizing, and Mulching (Type 1)
3,191 S.F.
Native Plugs
332 Each
Shrubs, 3 Gal Continuous
36 Each
Perennials, 1 Gal Continuous
226 Each
Trees, 2" Caliper B&B
4 Each
Double Shredded Hardwood Mulch, 3" Layer
35 C.Y.
Limestone Benches
10 Each
Limestone Cubes
10 Each
Salvaged Boulders
15 Each
2" River Rock
3 C.Y.
4"-5" River Rock
2 C.Y.
Flagstone Steppers
2 Tons
Boardwalk, 25'x6'
1 L.S.
12" Filter Sock
317 L.F.
Tree Protection Fence
200 L.F.
Electrical - Courtyard Site, Archery Building, and Stage
1 L.S.
Woodford S-3 Yard Hydrant and All Associated Items
Current operations at the Fair have temporary facilities for the air rifle and archery demonstrations. This project will provide a permanent solution for this activity, making it safer, easier to access, and more enjoyable for everyone. While relocating this portion to the north side of the courtyard, the stage where presentations are delivered will have to be moved to the south-west corner of the courtyard. This move will provide accessibility to all and will also reduce noise from adjacent activities at the fair. The North end of the courtyard will also be renovated for better circulation, permeable pavers, and native plantings will be installed.
ESTIMATED QUANTITIES:
Mobilization
1 L.S.
Demolition
1 L.S.
Construction Staking
1 L.S.
Class 10 Excavation, Common Excavation
150 C.Y.
Class 10 Excavation, Waste
50 C.Y.
Subgrade Preparation
328 S.Y.
Bioretention Cell Soil Media, 18" Layer
25 C.Y.
Choker Aggregate, 3" Layer
8 Tons
Aggregate Subbase, 12" Layer
29 Tons
6" Subdrain
261 L.F.
8" Subdrain
34 L.F.
Storm Sewer, Trenched 8" HDPE
22 L.F.
Subdrain Cleanout, Type A-1, 6"
4 Each
Subdrain Cleanout, Type A-2, 8"
1 Each
SW-512 Circular Area Intake, 18" W/ SW-604 Type 3A Casting
1 Each
SW-512 Circular Area Intake, 24" With Solid Casting
1 Each
8" Trench Drain
17 L.F.
Trench Drain PCC Channel
3 C.Y.
Corten Steel Channel. 12"
1 L.S.
6" PCC With Decorative Finishes, 6" Thickness
3 S.Y.
Permeable Pavers
280 S.Y.
Bedding/Joint Filler Aggregate, 2" Layer
29 Tons
Filter Aggregate Subbase, 4" Layer
59 Tons
Storage Aggregate Subbase, 8" Layer
109 Tons
PCC Edge, Permeable Paver Edge Restraint
504 L.F.
Soil Separation Fabric
315 S.Y.
Metal Landscape Edging
101 L.F.
Permanent Seeding, Fertilizing, and Mulching (Type 1)
3,191 S.F.
Native Plugs
332 Each
Shrubs, 3 Gal Continuous
36 Each
Perennials, 1 Gal Continuous
226 Each
Trees, 2" Caliper B&B
4 Each
Double Shredded Hardwood Mulch, 3" Layer
35 C.Y.
Limestone Benches
10 Each
Limestone Cubes
10 Each
Salvaged Boulders
15 Each
2" River Rock
3 C.Y.
4"-5" River Rock
2 C.Y.
Flagstone Steppers
2 Tons
Boardwalk, 25'x6'
1 L.S.
12" Filter Sock
317 L.F.
Tree Protection Fence
200 L.F.
Electrical - Courtyard Site, Archery Building, and Stage
1 L.S.
Woodford S-3 Yard Hydrant and All Associated Items
1 Each
Stage Building and All Associated Items
1 L.S.
Archery/Storage Building and All Associated Items
1 L.S.
Site Restoration
1 L.S.
Alternate
Alternate #1: Lead Encapsulation - DNR Pavilion Upstairs
This project is designed to restore/enhance two wetland pools on the Phelps tract of land in within the Okoboji View Wetlands Complex, Dickinson County, Iowa. Work under this project includes earthfill (berm construction), excavation (Spillway/Shallow Water), tile investigation, tile breaks, tile installation, a water control structure, erosion stone placement, and erosion control items. The contractor shall provide all materials, labor, and equipment as specified to complete the project as specified below and in the contract documents.
Contact Jeff Felts, jeff.felts@dnr.iowa.gov, for plans and contract documents.
Contact: Jeff Felts 515-250-3712 Jeff.Felts@dnr.iowa.gov
